The client (Party A):
The undertaker (Party B):
Project: Party A and Party B negotiated and negotiated with each other. Party A decided to entrust Party B to decorate the room. In order to ensure the smooth progress of the project, according to the relevant national laws and regulations, this contract (including the annex of this contract and all supplementary contracts) shall be signed for mutual compliance.
Article 1: Project Overview
1. Project address:__________________________________________________
2. Room specifications: Room type (style) Room kitchen
1, _____ room, total __________ square meters;
2, ______ hall, total __________ square meters;
3, ______ kitchen, total __________ square meters;
4, ______ bathroom, including __________ square meters;
5. ______ balcony, __________ square meters;
6, _______ aisle, total _______ square meters;
7, other (indicated parts) __________, total _______ square meters;
Total: construction area ___________ square meters;
3. Construction Content: For details, see Attachment (1) “Household Construction Construction Content List†and construction drawing of this contract.
4. Delegate method: _____________________________________
5. Project Commencement Date: _______ Year_______ Month ________ Day
6. Project Completion Date: __________ Year _________ Month _________ Day
Total days of construction: _____________ days
Article 2: Construction Price
The project price (amount in capital) is RMB. Please refer to Attachment (2) of this contract for “Household Decoration Engineering Materials Budgetâ€.
1, material section _______ yuan; 2, labor costs _________ yuan;
3, the design fee ________ yuan; 4, construction clear freight _________ yuan;
5, unloading fee ________ yuan; 6, management fee __________ yuan;
7. Taxes (3.41%) ___________ yuan;
8, other costs (marked content) _____________ yuan;
Article 3: Quality Requirements
1. The types, specifications, and names of the main materials used in the project are recognized by both parties. For details, please refer to Attachment (3) to the “Financial Statement of Home Improvement Engineering Materialsâ€.
2. Acceptance standards for works, the two sides agreed to refer to the city's local standards DB31/T30-1999 "residential decoration acceptance standards" provisions.
3. During construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and increase the additional costs, and shall sign another supplementary contract.
4. Quality Inspection and Supervision Department: City Interior Decoration Industry Association Home Decoration Professional Committee.
5. Where the materials and equipment purchased by Party A itself, the product quality is borne by Party A; the construction quality is the responsibility of Party B.
6. If Party A hires project supervisors, Party B must notify Party B prior to the start of the project to facilitate the work.
Article IV: Material Supply
1. Party B shall strictly follow the regulations of the relevant price regulations of the State and shall implement the plain price list for the materials used in this contract. See Attachment (2) of this contract for "Household Decoration Engineering Materials Budget". The materials provided by Party A shall be used in the decoration works stipulated in this contract, and shall not be used for other purposes without the consent of Party A. If Party B uses it for other purposes, Party B shall compensate Party A according to the double price of the misappropriated material.
2. If the materials and equipment provided by Party B do not meet the quality requirements or the specifications are different, they should be prohibited from use. If it has been used, Party B shall be responsible for the losses caused to the project.
3. Party A shall be responsible for purchasing and supplying materials and equipment. For details, please refer to Attachment (4) of this contract, "List of Party A's Decoration Materials Provided". It shall be a qualified product that meets the design requirements and shall be supplied to the site on time. If the delay arrives, the construction period will be postponed and the penalty will be imposed on the delay. 10% of the total amount of materials provided by Party A shall be paid to Party B as management fees. After the materials are accepted by Party B, Party B shall be responsible for the safekeeping. If the losses are caused due to improper storage, Party B shall be responsible for compensation.
Article 5: Payment Method
1. After the contract is signed, Party A shall pay 100% of the project materials and 50% of the construction cost. When the schedule is over half (year, month, and day), Party A will pay 40% of the construction fee for the second time. The remaining 10% of the balance shall be settled by Party A after acceptance of the project. (Note: Construction costs include labor costs)
Payment percentage
According to the payment method form:
Request for payment
Payment time payment percentage amount
Process content
Sign a contract for design and budget of 1,000 yuan
The date of signing the intention
Deducted on approved payments
Japanese Yen signing contract
Material 100%
yuan
50% construction fee
total
More than half of the progress
40% construction fee during construction
year month day
Completion acceptance 10%
Almanac
Increase project project signing project change 100%
The table should be in hand
Continued billing
Party A pays off the project price. For details, please refer to Attachment (7) of this contract: "Home Improvement Project Settlement Form". Party B shall issue a unified invoice to Party A for handing over and issuing the decoration project warranty card. For details, please refer to the attachment of this contract (8) "Home decorating project Engineering Quality Warranty Card.
Party A's failure to pay on the due date is a breach of contract. Party B has the right to stop the construction. Acceptance of the project price that is not settled may not be delivered.
2. If there are any changes or changes in the project during the construction, please refer to Attachment (5) of this contract for the "House Decoration Engineering Project Change Form." The two parties shall sign a supplementary contract, and Party B shall be responsible for issuing a construction change order to inform the person in charge of the construction site. . Increase or decrease the price of the project and settle it on the spot.
3. If Party A does not prepay the project price within the time limit specified in the contract, Party B shall pay Party B at least 1% of the unpaid project price for each overdue day.
4. If Party A mortgages the bank in the decoration of the house, it must submit the voucher and related documents (copy) of the mortgage to Party B.
Article 6: Project Duration
1. If delays are made due to the cause of Party B, 1% per day as a penalty fine is paid to Party A until the fees are deducted. If delays are made due to Party A's reasons, 1% of the labor cost of the decoration project shall be paid to Party B as a late work fee for each day of delay.
2. The materials and equipment selected by Party A shall affect the quality and duration of the project due to unqualified quality. The rework cost shall be borne by Party A. Due to the quality accidents caused by Party B's construction, the rework cost shall be borne by Party B and the duration shall not change.
3. During the construction, due to project quality problems and the disagreement between the two sides resulting in suspension of work, both parties did not follow the deadline for work delays or delays. The parties should actively request the mediation or arbitration departments of relevant departments to coordinate and handle the disputes as soon as possible so as to continue the construction.
4. In case of re-rework due to Party A's reason during construction, or due to Party A's alteration of the construction content, the visa will be required. Party A shall bear all construction expenses. If Party B causes rework, Party B shall bear the responsibility for the construction period. constant.
5. During the construction, Party A would notify the construction personnel without permission of Party B to change the quality of the construction content and delay the construction period. Party A shall be responsible.
Article 7: Project Acceptance
1. Acceptance of project quality is detailed in Annex (6) of this contract, “Quality Acceptance Form for Home Improvement Projectsâ€. Except for concealed projects that need to be accepted by section, after the completion of the project, Party B organizes Party A to perform the final acceptance. Both parties handle project settlement and handover procedures.
2. After Party B notifies Party A of the process acceptance and acceptance of completion, Party A shall come and accept the inspection within three days. If Party B lapses, it shall be deemed that Party A will automatically waive its rights and deemed to be qualified. If there is any problem, Party A shall be responsible. Party A will move into the apartment and will be deemed as qualified.
3. Party A shall notify Party B in a timely manner and set a date if it cannot be accepted within the time limit specified by Party B. However, Party A shall acknowledge the completion date of the process or project and shall bear Party B's care fees and related expenses.
Article 8: Other matters
1. Party A
1. It is necessary to provide the floor plan of the house approved by the realty management department and the water, electricity, and gas circuit diagrams, or to provide the floor plan of the house and the water, electricity, and gas circuit diagrams, and to perform the on-site delivery to Party B.
2. For secondary decoration works, all or part of the houses shall be vacated to clear obstacles that affect the construction. For the furniture and furnishings left in houses that can only be partially vacated, the necessary protective measures must be taken. All of them must go through formalities with Party B and bear the expenses.
3. If it is really necessary to demolish or change the original building structure or equipment or pipelines, it should go through procedures with the local housing management department and bear the relevant expenses. If you need to temporarily use common parts during construction, you should say hello to your neighbours.
2. Party B
1. Should present its business license, membership certificate, or construction qualification; if it is a subordinate branch, it must also have a certificate from a superior company; the salesman must have a legal representative's commission certificate.
2. The designation (name) is the site representative of Party B, who is responsible for the performance of the contract, organizes the construction according to the contract, and completes the construction tasks on time and in good quality.
3. Responsible for the safety of the construction site, prevent fires, certify posts, civilized construction, and prevent accidents such as blockage of pipes, leakage of water, power outages, damage to goods, etc., and affect others. In case of occurrence, it must be repaired or compensated as soon as possible.
4. Strict performance of the contract, the implementation of the credit duration, if delayed due to delays in completion, such as material, work or excuse to induce Party A to withdraw funds, the investigation will be based on breach of contract.
5. The warranty responsibility shall be borne within the scope of the construction work. The warranty period shall be 12 months from the date of acceptance of the project completion A project inspection income.
Article 9: Liability for breach of contract
After the contract comes into effect, if the party terminates the contract without authorization during the performance of the contract, it shall pay the other party according to the total contract amount of 5% as the breach penalty. If the contract is cancelled without authorization and the actual damage caused by the other party exceeds the liquidated damages, compensation shall be made.
Article 10: Dispute Resolution
1. During the performance period of the contract, if there is a dispute between the two parties, the two parties shall resolve the dispute without prejudice to the progress of the project. Or on the basis of this contract and the unified invoice issued by Party B, complaints were made to the Home Decoration Professional Committee of the Municipal Interior Decoration Industry Association to request resolution.
2. If the parties are unwilling to resolve through negotiation or mediation, or if consultation or mediation fails to resolve, they may apply for arbitration in accordance with this contract—Arbitration Commission;
Article 11: Changes and termination of the contract
1. After both parties have signed and signed the contract, both parties must strictly abide by it. If any party needs to change the content of the contract, it should sign a supplementary agreement after mutual agreement. If it is necessary to terminate the contract, the party that proposed the termination of the contract must submit it in written form. The liquidated damages shall be paid at 10% of the total price of the contract and the formalities for terminating the contract shall be handled.
2. In the construction process, either party shall terminate the contract and submit it to the other party in written form. After the parties agree to complete the liquidation formalities, after the conclusion of the termination contract agreement, the termination of the contract can be regarded as the termination of the contract.
Article 12: Effectiveness of the contract
1. This contract and the annexes of the contract are stamped by both parties and become effective after being signed.
2. The supplementary contract has the same legal effect as this contract.
3. This contract (including the attachment of the contract and the supplementary contract) is in one copy, and both parties A and B and the witness department are in possession.
Party A (owner): (signature) Party B: (signature)
Address of residence: Address of company:
Postal code: Postal code:
Work unit: Legal representative:
Construction Contract Decoration House Decoration Interior Decoration Door Price Decoration Project Budget Table Bathroom Design Bathroom Door Bathroom Leakage
Printed Carpet Co., Ltd. , http://www.hot-carpets.com